Terms of Service

1. Introduction

Welcome to Garcia Renovations. By accessing our website, requesting services, or engaging with our company, you agree to be bound by these Terms of Service. If you do not agree with any part of these terms, please do not use our services.

2. Definitions

"Company" refers to Garcia Renovations Inc., its owners, employees, and authorized representatives.
"Client" refers to any individual or entity requesting or receiving services from the Company.
"Services" includes but is not limited to roofing installation, repair, replacement, gutter installation, gutter repair, gutter cleaning, inspections, and related construction services.

3. Estimates and Quotes

All estimates provided by Garcia Renovations are valid for 30 days unless otherwise stated. Estimates are based on the information available at the time and may be subject to change if:

• Unforeseen conditions are discovered during the project (e.g., hidden rot, structural issues)
• The client requests changes to the scope of work
• Material prices increase significantly between estimate and project start

Verbal estimates are for informational purposes only and are not binding. Only written estimates signed by both parties constitute a binding agreement.

4. Client Responsibilities

As a client of Garcia Renovations, you agree to:

• Provide accurate information about your property and project needs
• Ensure clear access to work areas as needed
• Obtain necessary permits unless otherwise agreed in writing
• Notify your neighbors of upcoming work when required
• Make payments according to the agreed schedule
• Communicate any concerns promptly

5. Payment Terms

Payment terms are specified in your project contract. Generally:

• A deposit may be required to secure your place on our schedule
• Progress payments may be due at specified milestones
• Final payment is due upon completion and your satisfaction with the work
• We accept cash, check, credit card, and financing options

Late payments may incur interest charges or suspension of work. Returned checks are subject to a $35 fee.

6. Warranties

Manufacturer Warranties: Materials used in your project come with manufacturer warranties that vary by product. We will provide you with all warranty documentation upon completion.

Workmanship Warranty: Garcia Renovations warrants our workmanship for a period of 5 years from project completion, unless otherwise stated in your contract. This warranty covers defects in installation that result in leaks or failure. It does not cover damage from acts of nature, improper maintenance, or normal wear and tear.

Warranty Claims: To file a warranty claim, contact us immediately. We will inspect the issue and remedy any covered defects at no cost to you.

7. Insurance

Garcia Renovations maintains:

• General Liability Insurance
• Workers' Compensation Insurance as required by law
• Bonding as applicable

Certificates of insurance are available upon request.

8. Project Delays and Changes

We strive to complete all projects on schedule, but delays may occur due to:

• Weather conditions (rain, snow, high winds, extreme temperatures)
• Material availability issues
• Unforeseen structural conditions
• Client-requested changes
• Permit approval delays

If you request changes to the original scope of work, we will provide a written change order detailing any adjustments to cost and timeline. Work will not proceed on changes until the change order is signed.

9. Property Protection and Cleanup

We take reasonable precautions to protect your property during construction, including:

• Using tarps and plywood to protect landscaping
• Placing dumpsters to minimize impact
• Magnetic sweeping for nails and debris
• Daily cleanup of work areas

However, construction inherently involves some risk. We are not responsible for pre-existing conditions or damage to underground lines, sprinkler systems, or invisible structures not marked prior to work.

10. Customer Satisfaction

Your satisfaction is our priority. If you have any concerns during or after your project, please contact us immediately. We will work with you to address any issues promptly and fairly.

11. Intellectual Property

All content on our website, including logos, images, text, and designs, is the property of Garcia Renovations and protected by copyright laws. You may not reproduce, distribute, or use our content without written permission.

12. Limitation of Liability

To the maximum extent permitted by law, Garcia Renovations shall not be liable for any indirect, incidental, special, consequential, or punitive damages arising out of or relating to our services. Our total liability shall not exceed the amount paid by you for the specific services in question.

13. Indemnification

You agree to indemnify and hold harmless Garcia Renovations, its employees, and agents from any claims, damages, or expenses arising from your failure to provide accurate information, your violation of these terms, or your use of our services in a manner inconsistent with these terms.

14. Governing Law

These Terms of Service shall be governed by and construed in accordance with the laws of the State of [Your State], without regard to its conflict of law provisions. Any legal action arising out of these terms shall be filed in the courts of [Your County], [Your State].

15. Changes to Terms

We reserve the right to modify these Terms of Service at any time. Changes will be effective immediately upon posting to our website. Your continued use of our services after changes constitutes acceptance of the revised terms.

16. Severability

If any provision of these terms is found to be unenforceable, the remaining provisions shall remain in full force and effect.

17. Entire Agreement

These Terms of Service, together with any project-specific contracts, constitute the entire agreement between you and Garcia Renovations regarding our services.